About this document

Lorenzo Shipping vs. BJ Marthel Case Analysis by Shariefa is a document available to read on EtoBox.

1) Respondent supplied cylinder liners to Petitioner but delivered them almost 6 months after Petitioner issued two Purchase Orders. 2) The Purchase Orders omitted delivery dates that were stated in an earlier Quotation from Respondent. 3) The court found that the Purchase Orders, which omitted delivery dates, represented the final agreement between the parties rather than the earlier Quotation. Since the Purchase Orders did not specify that time was of the essence, Petitioner could not claim late deliver

Author

Shariefa

Language

EN