Can I read Arbitration Petition 593 of 2019 Summary on EtoBox?

Arbitration Petition 593 of 2019 Summary by Abhishek Salian is a document available to read on EtoBox.

What is Arbitration Petition 593 of 2019 Summary about?

1) The petitioner developer has faced significant delays in completing a housing reconstruction project for the respondent housing society. The development agreement was signed in 2010 but construction is still incomplete nearly a decade later. 2) The respondent society terminated the development agreement in 2015 due to lack of progress and lost faith in the petitioner. The petitioner has also defaulted on rental payments for temporary accommodation of over Rs. 3 crores. 3) Despite court orders directing

Author

Abhishek Salian

Language

EN