Can I read Philippines Expert v. V.P. Eusebio Case Summary on EtoBox?

Philippines Expert v. V.P. Eusebio Case Summary by Reigh Harvy Canta is a document available to read on EtoBox.

What is Philippines Expert v. V.P. Eusebio Case Summary about?

The Supreme Court ruled that the respondent contractor had not defaulted on its obligations under the construction contract. This was a mixed question of fact and law that is better addressed by the lower courts, whose factual findings are generally binding unless not supported by evidence. Both lower courts found that the delay in completion was not primarily attributable to the respondent, but was due to the project owner

Author

Reigh Harvy Canta

Language

EN