Can I read Bhagheeratha Engineering - Delhi HC on EtoBox?
Bhagheeratha Engineering - Delhi HC by Rituraj is a document available to read on EtoBox.
What is Bhagheeratha Engineering - Delhi HC about?
The High Court of Delhi addressed two petitions challenging an Arbitral Award regarding delays in a construction project between Bhagheeratha Engineering Ltd. and the National Highways Authority of India. The Arbitral Tribunal found that 45 months of delay were attributable to the petitioner, while 31 months were jointly attributable to both parties, and ruled in favor of the respondent for compensation. The court upheld the Tribunal
- Author
- Rituraj
- Language
- EN